Planning Issues In The Construction Industry Construction Essay

Planning Issues In The Construction Industry Construction Essay Construction is an everlasting activity across the globe. Its profitability like of any other business fluctuates according to the law of demand and supply. In most countries, construction activity constitutes 6-9% of the gross domestic product (GDP) and constitutes more than half of the fixed capital formation as infrastructure and public utilities capital works required for economic development. Construction activity contributes to the economic development of a country. The GDP per capita and the investment in the construction per capita generally follow a straight line relationship, that is construction activity increases with the increase in per capita income. Construction projects are intricate and time-consuming tasks. For the total success of any particular project a wide chain of specialized services is necessary for the timely completion of the project. During the construction process, itself even a project of small or medium proportions requires many attributes, materials a nd involves many different types of operations. The assembly process must follow a natural order of events that, in total combination, constitutes a complicated pattern of individual time requirements and restrictive sequential relationships among the many segments of the structure (Project Quality Management in Construction, K. Lambrou, G.J. Besseris and C. Alafodimos, MSc in Quality Management, TEI of Piraeus and University of Aisley).Mismanagement of resources has become a prevalent problem in many construction firms. This mismanagement of resources contributes to numerous construction firms ineffectiveness and frequent failures each year. Hence, it is necessary to take appropriate steps and follow the process to improvise the output of construction industry by using proper planning methods and techniques. This can be done through adoption of modern and improvised planning techniques in construction industry such as CPM, PERT, Supply Chain Management etc, which will be discussed in detail in main dissertation work. In the literature review of planning issues in construction industry, different aspects of social-cultural-economic importance of planning and modern planning techniques has been highlighted. This dissertation focuses on analyzing the major hindrances caused by the positive and negative issues in planning and execution phase of the project. 2. Background Planning is a key ingredient in the successful completion of any construction project. It provides the road map for the project to follow and the milestones by which its progress is measured. To understand the loopholes in the planning process it is necessary to dismantle the planning objectives, so that all the aspects regarding the project could be thoroughly capitalized. Four planning objectives which characterize the whole of the planning process are execution of work, coordination of all the activities, control over the materials and manpower and forecasting. Safety is a major concern to every successful construction project because of humanitarian concern for the workers and the cost ramifications of a poor safety record. Major construction firms had proposed the usage of network planning techniques, mainly because of owners demand. The relationship between project planning and construction safety is sometimes subtle, and the impact it has on the project is not as readily apparent as the importance of planning and safety as separate entities. A comprehensive planning and scheduling specification system can aid in the planning of job sequence, financial needs, workforce needs, material needs, and equipment needs. It also can aid the scheduling of actual activity start or completion and provide feedback to control the schedule, cost, and use of resources. A critical step in the execution of any construction project is the selection of planning and scheduling specification clauses to be included in the construction contract. Numerous project characteristics should be taken into account when determining which planning and scheduling clauses to be included. Project is a mission, undertaken to create a unique facility, product or services within the specified scope, quality, time and costs. With the emerging global opportunities, projects cross geographical boundaries, corporate channels, traditional systems and cultural diversities. The knowledge areas needed to manage such projects comprise project management techniques, general management practices and technology-related subjects. The project management techniques of planning, scheduling and controlling are the tools and devices that bind the subjects knowledge areas. These techniques can be applied to all types of projects. This research focuses on the application of all these techniques in the construction industry. It is widely recognized that effective planning can play a major role in the success of projects. Whether project success is based on the traditional measure of time, cost and quality or newer measures of critical success factors (Westerveld, 2003), effective planning can also contribute to the prevention of accidents and ill health of site personnel (Duff and Suraji, 2000; HSE, 2003). These objectives become increasingly difficult to achieve, however, in construction projects. Construction sites can be extremely busy places where the working environment is ever changing. Unfortunately, in addition to this, the construction industry tends to be under resourced and under planned in relation to other industries (Egan, 1998), which can lead to a crisis management approach to production risk, a feature of construction culture which can impact heavily on health and safety. Despite this, activities requiring intensive planning as those required in a temporary rail possession, almost invari ably run smoothly. There is little chance of an unsafe incident, due to the heightened risk awareness resulting from the meticulous planning. 3. Aims and Objectives To study various minute details affecting the process of planning. The objective of this research is to assess the modern methods of planning and scheduling a construction contracts which can be applied in todays construction industry and to also discuss the issues involved in the application of those tools. To compare and analyze a planning strategy which has a solution for various issues in the planning process. 4. Research Methodology The research methodology is the approach through which the researcher collects the data useful for the chosen topic and then the analysis is done on the basis of that. In my dissertation, I will be using qualitative research as means to study planning and scheduling in construction contracts. 5. Scope and Limitations of Dissertation The limitations of the dissertation are: This research targets only construction industry, hence the results cannot be implied on the others sectors. This analysis will be done for Indian and UK industry. However, the study done on India and UK is not necessary applicable for other nations as well as because of cultural differences. Planning techniques for different countries is different which adds to more misery. The unavailability of proper planning and management techniques, which could possibly solve the issues of planning even when proper resources are not available. Construction Industry has flourished domestically as well as globally over the years. Economic development of any particular country also largely depends upon the construction projects. Major factors that affect the overall result of any project would be size, complexity, quality, productivity, completion time and cost. These factors would be achieved only when proper planning is done, which forms the base of construction management. A project plan is always formulated during the planning phase. Planning in its broader perspective, involves advance thinking as to what is to be done, what are the activities, how it is to be done, when it is to be done, where it is to be done, what is needed to do it, who is to do it and to ensure that it done. A project plan would be adversely affected if cost overruns and delays take place. The effect of past construction experience, on the quality of management in general and on planning effectiveness in particular, is addressed only rarely in const ruction-management research; the few studies doing so explicitly are in agreement with the findings of the present study. NEDO (Faster 1983) reports the contractors inexperience in similar projects as a major source of difficulty in construction [Faster building for industry (1983). NEDO-Building EDC, National Economic Development Office, London, England.]. All the perseverance put into the invention of new techniques did not gave the satisfying results in the construction planning sector (Choudhury 1981, Mason 1984, Morton 1983). Sometimes people fail to recognize the difference between planning and scheduling. Progress in the usage of new computer techniques has resulted in the misconception of standardization of project scheduling. Projects have been a part of our society for quite a long era. Indication of total efficiency would be seen by completing project on time, but construction process is subjected to too many fluctuations and unforeseeable factors which results from many sources (Sadi. A. Assaf, Sadiq Al-Hejji, (2005)). Construction organization lives in the ever-changing and their effectiveness depends on their ability to adapt to new demands and opportunities. This industry needs to adjust itself to the changes occurring in its working environment in order to become effective. Construction projects are intricate and time-consuming tasks. The total development of a project normally consists of several phases requiring a diverse range of specialized services. In progressing form initial planning to project completion, the typical project passes through successive distinct stages that demand inputs from such disparate groups as financial organizations, government agencies, engineers, architects, lawyers, surety companies, contractors, and building trade-persons. Most challenging part of these modern techniques is implementing these methods to achieve a particular goal or task. Construction Industry faces a lot of problems because of the working patterns and inefficient planning techniques to reach to complete a particular function. Following the modern planning techniques reduces the dilapidation of resources and economically strengthens the company. A constant focus should be given on the improvisation techniques which include mutually collaborating one or more techniques which would lead to a profitable project and reduce the loss due poor performance and cost overruns. The constructions industry in India and UK has realized the importance of the proper usage of modern planning techniques which has improvised the margins of profits and truncate the overall project cost. In India planning is an open process (Planning in India RICHARD S. ECKAUS MASSACHUSETTS INSTITUTE OF TECHNOLOGY ).If design completion is not done at proper time it would prove to be costly, as it would lead to construction delays. In India a prevalent method to planning is not sufficient as there are many situations which includes Limitation or inexpertness of human beings in there respective fields (Human Errors). Influence of external factors beyond human control (E.g. Natural Hazards: this could have an adverse effect on the planning process). The external components interact with the construction firm from outside of the organizations environment. Such external components are material suppliers, financial institutions, and surety companies, end users of products, owners, and architects. The project is also influenced by external causes due to scarce availability of resources in the market (Techniques and Technology). The project covers important framework of an integral system; therefore considerable economic or technical consequence could result from faulty usage. (An approach to planning and control of advanced projects Giorgio Caroni, Roland0 Matteelli and Alfred0 Berti) In order to have a competitive edge over other construction companies, perfectly planning techniques should be used. Main Body CASE STUDY: Even though India is one of the developing countries the approach towards planning is comparatively more advanced as compared to other developing countries. (Planning in India, RICHARD S. ECKAUS, MASSACHUSETTS INSTITUTE OF TECHNOLOGY). In India, for small scale project ranging between 1million £-10million £ specific planning techniques cannot be implemented, as a lot of unavoidable problems usually arise due to many reasons. Comprehensive survey of the location of the project clearly marks the project area and its boundaries. Soil investigation is to be done to ascertain the soil strength so as to decide the type and other specific details of the foundation. Depending upon the soil investigation reports, finalize the type of foundation i.e., pile foundation or open foundation up to hard strata strength. Necessary approvals, clearances, no objection for all the concerned government departments, local or self governing authorities should be obtained before starting the project. To ascertain whether any public utility service lines like Water pipe lines, sewage pipe lines, electrical cables or over head lines, telephone line or any other Public/Private items or assets are crossing /passing through the designated project area. Specific measures must be taken to relocate the service lines or public assets before starting the project. Drawings incorporating all the specific details, dimensions and other specifications must be accurate and must be got approved from all the relevant authorities before starting the work If any of the above fundamental issues are neglected at the planning stage, you are steadily heading for a project period over run and project cost overrun. TYPICAL CASE STUDIES FROM INDIA BUILDING PROJECT OF CBI(CENTRAL BEAURAU OF INVESTIGATION) BUILDING 1) Name of Work : Construction of Administrative Building including all infrastructure Amenities for C.I.D Pune. at Pune 2) Client : Maharashtra State Police Housing Welfare Corporation. Limited, Mumbai 3) Tender Work Order No : PHC/TB/CID PUNE/1152/2005 Dated 15.07.2005 from General Manager 4) Contractor : M/s. Deepa Engineers, 42, Welfare Chambers, 1st Floor, Sector-17, Vashi, Navi Mumbai 400 705 5) Architect : M/s. Arc-Aids. Pune 6) P.M.C : M/s PP Ventures, Pune 7) Tendered Amount : 5, 43, 04,161/- 8) Date of Starting : 02.09.2005 9) Stipulated period of completion : 31.05.2007 10) Area as per tender : 5483.57 Sq.Mtr 11) Area as per actual construction : 7217.19 Sq.Mtr. Including Common Facility. 12) Common Facility Area : 109Sq.Mtr 1) Septic Tank = 36 Sq.Mtr 2) Meter Room = 19 Sq.Mtr 3) Pump House = 54 Sq. Mtr 13 Area Constructed : 7108.19 Sq.Mtr (7217.19-109 = 7108.19 Sq.Mtr) 14) Actual date of completion/ : 31.03.2009 Taking over 10.07.2009 15) Difference in Area : 1669.62 Sq.Mtr. 16) R.A. Bill No. 21st (pending) : 30,70,629.00 17) Final Bill yet pending : 26,01,169.00 18) Security Deposit : 13,57,604.00 19) Retention money deducted From 20th R.A. Bill : 1,38,747.00 20) Retention money deducted From 21th R.A. Bill : 1,52,052.00 21) Extra Items Amount : 1,83,210.00 22) Inauguration Expenditure : 3,10,000.00 23) Bank Guarantee En cashed : 13,57,604.00 Total Claims overdue : 91,71,015.00 + Difference in Constructed Area amount Conclusion Departmental interaction between various service agencies of the state, like the police housing Department and PUNE Municipal Corporation must have been initiated at the planning stage of the tender itself. Though the project is commissioned successfully on 10th July-2009 and the C.B.I has occupied the Administrative Building, with all the proposed amenities the Contractor has suffered huge financial losses. Presently the case is under arbitration Justification for the delay of work 1) M/s. Arc-Aids, (Architect) M/s. PP Ventures, Pune (PMC) were new to the department lack of coordination between them with Police Housing and the contractor resulting in bad delay in furnishing the requisite drawings and other relevant details for the timely execution of the work. 2) Delay due to the shifting of approx One Meter Diameter Water pipe line of Pune municipal corporation which was not shown in the layout drawing of the tender, passing through the site feeding water supply to Pune City Delay 10 Months. The work was coordinated by Deepa Engineers and executed by Pune Municipal Corporation without any financial obligations to PHC. Drawings must incorporate all the details accurately, after carrying out proper survey of the project area. 3) Non releasing of the payments in time by holding of Running Bills payment by imposing heavy penalty as given below, which was against the terms conditions of the Tender, since the delay was caused by reasons beyond the responsibility control of the contractor Sr.No. Particulars No. of days Amount to be recovered from Bill in Rs. 1 Rs. 1000/-per day w.e.f. 1/6/07 to 15.01/08 229 2,29,000/- 2 Rs. 5000/-per day w.e.f. 16/01/08 to 15/02/08 31 1,55,000/- 3 Rs. 10000/-per day w.e.f. 16/02/08 to 12/05/08 87 8,70,000/- 4 Rs. 15000/-per day w.e.f. 13/5/08 to 30/06/08 49 7,35,000/- 5 Rs. 65000/-per day w.e.f. 1/7/08 to 10/07/09 375 2,43,75,000/- Total 771 2,63,64,000/- This holding of payment was waived and released by Hon. S.S. Virk after joining as M.D. of Police Housing Corporation and assured that the penalty will be waived and the difference in area constructed will be consider after completing the work. Accordingly the work is restarted and completed on 31.03.2009 and handed over on 10.07.2009. Month wise requirement of funds if predicted during the plannings stage itself, the payment schedule flow of money will not be hampered. B) Name of Project: 1) Construction of three storeyed of 300 seated Post Graduate Hostel including internal Water supply, Sanitary installation, Drainage wok and internal electrification work for Vishweshwarayya National Institute of Technology, Nagpur, India Name of Contractor : M/s. DEEPA ENGINEERS, 42, WELFARE CHAMBERS, 1ST FLOOR, SECTOR-17, VASHI, NAVI MUMBAI Estimated Cost : 5,33,56,856/- Tendered Amount : 9,34,63,099.00 Time allowed : 16 Months including monsoon Period Commencement Date : 12.07.2007 Stipulated date of completion : 11.11.2008 Security Deposit : 46,73,155.00 (Bank Guarantee) Project Management : Central Public Works Department, Superintending Engineer, Central Circle, Nagpur. Architects : do B) Name of Project: Construction of Additional storey (100 seated) over proposed 300 seated Post Graduate Hostel at Vishweshwarayya National Institute of Technology, Nagpur. Name of Contractor : M/s. DEEPA ENGINEERS, 42, WELFARE CHAMBERS, 1ST FLOOR, SECTOR-17, VASHI, NAVI MUMBAI Estimated Cost : 1,78,70,130.00 Tendered Amount : 2,36,39,902.00 Commencement Date : 28.11.2008 Stipulated date of completion : 27.05.2009 Security Deposit : 11,82,000.00 (Bank Guarantee) Time allowed : 6 Months Project Management : Central Public Works Department, Superintending Engineer, Central Circle, Nagpur. Architects : do Actual date of Completion : 31.03.2010 Parameter adopted for mix design for RCC works Ready Mix Concrete Nominal maximum size of aggregate : 20 mm angular as per C.P.W.D. description Degree of quality control : Good Type of Exposure : Moderate Maximum water cement Ratio : 0.50 Cement Content : 410/Kg/cum of concrete Type of Cement used : OPC 43 grade Conforming to IS: 8112 Sand : Coarse sand as per CPWD Specification Approved Admixtures conforming to I.S. 9103 permitted Fly wash shall not be used in R.C.C The Contractor shall submit the Mix Design Report from Approved Laboratory and get it approved from the Engineer-in-Charge Causes for the delay in completion of the project. Inaccurate Soil Investigation Report. The Original depth of Excavation, for Foundation fixed as 5ft(1.52 m) as per tender. At the time of actual execution the depth upto loft which resulted in huge quantity variation in excavation, quantity of steel and other items necessitating further approvals from all competent authorities. This project cost overrun and period overrun could have been avoided if proper soil investigation was carried out before tendering A Major defect in planning was the decision to have an additional floor with 100 seats after the completion of the hostel building up to 3rd floor by the contractor. The right decision to have a Four storied 400 seated Hostel building initially would have saved the Project period by at least 4 months Also there could have been a saving of the total Project cost by at least 03 % TABLE OF MILESTONE (S) CASE B(1) S. No. Financial Progress Time allowed (from date of start) Amount to be withheld in case of non achievement of milestone 1 All P.C.C. and brick works up to plinth level 120 days In the event of not achieving the necessary progress as assessed 1% of the tendered value of work will be withheld for failure of each milestones 2 Complete R.C.C structure up to terrace level 240 days 3 All brick work , flooring, internal plaster, fixing of door frames and windows etc along with all related items 355 days 4 Water proofing to terrace slab, external plaster and painting, fixing of all electrical and water supply, sanitary fitting etc. complete along with handing over of building including external service connections complete. 16 months TABLE OF MILESTONE (S) CASE B(2) S. No. Physical Progress Time allowed (from date of start) Amount to be withheld in case of non achievement of milestone 1 All R.C.C. Columns 30 days In the event of not achieving the necessary progress as assessed 1% of the tendered value of work will be withheld for failure of each milestones 2 Complete R.C.C and brick work up to terrace level 90 days 3 All brick work , flooring, internal plaster, fixing of door frames and windows etc along with all related items 150 days 4 External plaster and painting, fixing of all water supply, sanitary fitting etc. complete along with handing over of building including external service connections complete. 6 months Results from the Case Study: IN GENERAL VIEWS Table 1 List of causes of delay which may affect the overall planning is categorized below (Causes of delay in large construction projects, Sadi A. Assaf *, Sadiq Al-Hejji) No. of. Causes of delay affecting the planning process Group 1 The Original contract duration is very short Project 2 Disputes between various parts Project 3 Inadequate definition of substantial completion Project 4 Ineffective delay penalties Project 5 Type of construction contract (Lump sum contract, construction only,) Project 6 Type of project bidding and award ( lowest bidder) Project 7 Delay in payments by the owner Owner 8 Delay to furnish the site to the contractor by the owner Owner 9 Revision orders by the owner during construction phase Owner 10 Late in changing and approving the design documents by the owner Owner 11 Delay in approval of drawings and the sample materials Owner 12 Improper communication by owner and other parties Owner 13 Unwillingness to make proper decisions Owner 14 Disagreements occurring between joint-ownership of the project Owner 15 Absence of incentives for contractor for finishing the work ahead of schedule Owner 16 Discontinuation of work by owner Owner 17 Financial problems faced by contractor Contractor 18 Problems in sub-contractors schedule in execution work Contractor 19 Alterations during construction due to some minor errors Contractor 20 Affray between contractor and other parties Contractor 21 Inappropriate site management by the contractor Contractor 22 Inappropriate communication by contractor with other parties Contractor 23 Poor planning of project by the contractor Contractor 24 Improper construction techniques implemented by contractor Contractor 25 Postponement in sub-contractors work Contractor 26 Inadequate standard of work by contractor Contractor 27 Periodic changes of sub-contractors Contractor 28 Poor qualification of technical staff Contractor 29 Mobilization problems at site Contractor 30 Postponement in inspection and testing by consultant Consultant 31 Delays in the approval of major changes in the scope of work by consultant Consultant 32 Inflexibility shown by the consultant Consultant 33 Improper coordination between consultant and other parties Consultant 34 Slow to review and approve the documents by the consultant Consultant 35 Issues between the consultant and the design engineer Consultant 36 Inadequate experience of consultant Consultant 37 Mistakes in the design documents Design 38 Delay in delivering the design documents Design 39 Imperfect details in drawings Design 40 Complications in understanding of the project design Design 41 Incomplete data collection survey before design Design 42 Confusion in owners requirements by design engineer Design 43 Insufficient design-team experience Design 44 Low amount of usage of advanced engineering design software Design 45 Shortage of construction materials in market Materials 46 Alterations in the type of materials and specifications during the construction Materials 47 Immobilization of material Materials 48 Damage of sorted material while they are needed urgently Materials 49 Delay in manufacturing special building materials Materials 50 Late procurement of materials Materials 51 Late in selection of finishing materials due to availability of many types in market Materials 52 Equipment breakdowns Equipment 53 Shortage of equipment Equipment 54 Low level of equipment-operators skill Equipment Equipment 55 Lack of high-technology mechanical equipment Equipment 56 Shortage of labours Labours 57 Unqualified workforces Labours No. Causes of delay Group Labours 58 Nationality of labours Labours 59 Low productivity level of labours Labours 60 Personal conflicts among labours Labours 61 Effects of subsurface conditions (e.g., soil, high water table, etc.) External 62 Delay in obtaining permits from municipality External 63 Hot weather effect on construction activities External 64 Rain effect on construction activities External 65 Unavailability of utilities in site (such as, water, electricity, telephone, etc.) External 66 Effect of social and cultural factors External 67 Traffic control and restriction at job site External 68 Accident during construction External 69 Differing site (ground) conditions External 70 Changes in government regulations and laws External 71 Holding up the work from the important utilities i.e., water, electricity etc External 72 Final inspection has been delayed by a third party External Literature Review: Definitions and Concepts of Planning and Planning issues Planning can be defined as any one of the following: 1. A decision-making process. 2. A process of anticipatory decision-making to decide what and/or how to perform actions due at some point in the future. 3. A process of integrating interdependent decisions into a system of decisions. 4. A hierarchical process evolving from general guidelines to objectives, to the elaboration of means and constraints that lead to a detailed course of action. 5. A process that includes part or all of a chain of activities comprising information search and analysis, development and design of alternatives, analysis and evaluation of alternatives and choice making. 6. The systematic employment of procedures (standardized and formal to varying degrees). 7. Documented presentation, in the form of plans. (Is construction project planning really doing its job? A critical examination of focus, role and process, A. Laufera; R. L. Tucker, Department of Construction Management, Technion IIT, Haifa, Israel b Construction Industry, Institute, The University of Texas at Austin, TX, USA) Social-Cultural-Economic Importance of Planning(POSTIVE AND NEGATIVE) Cultural Aspects: (International Measurement of the Economic and Social Importance of Culture, Prepared by John C. Gordon and Helen Beilby-Orrin) . The Australian statistical office

The Lost Generation

Both Remarque’s â€Å"All Quiet on the Western Front† and Hemingway’s â€Å"The Sun Also Rises† relate to the theme of hopelessness during the lost generation. Remarque’s story is set during the war from a younger German soldier, Paul, through him the suffering and difficulties are presented as fruitless and with out a main goal to look forward to when they return home. Throughout the military travels of the younger soldiers like Paul, Remarque’s view on wars disadvantages on people are clearly stated through the eyes of Paul. Towards the end of his life, he grows happy to die and is glad to pass away from all the pain emotionally and physically he and his comrades had to endure during the battle. Carrying on through the book is the sense of empty hopelessness that nothing will become good and there is nothing to look forward to after their arrival home. On the other side, Hemingway’s older veteran characters, Jake and Brett, play the role of two empty people who are looking for direction in life after the devastating war. Jake however becomes a redeemable character through his journey to overcome his psychological and physical damage from the war and gains sympathy. However Brett does not earn any more respect or accomplishes any growth in overcoming her war wounds. This takes its own path in the end when Jake moves on from Brett’s taunting attitudes and starts to gain his balance in life again. Hemingway’s hopelessness is conveyed more positively than Remarque’s critical outlook on war. Throughout both book the characters struggle with their emotional difficulties to stay attuned to their prewar lives and struggle with hope for the future. However Hemingway takes the path of a more positive ending while Remarque creates a happy doom for his brave, suffering characters. There are many parallels between the characters in each book enough though the themes and perspectives are entirely different. The main point serves the same purpose, whereas the lost generation was hopeless unless they rarely saw a glimpse of the future after recovery. The tone of the overall book has an almost empty and predictable attitude about it, the men have no hope for themselves, and they do not convey a sense of need to get home or to survive but merely to continue to take orders until the end. The hopelessness conveyed by the characters in â€Å"All Quiet on the Western Front† is the kind of hopelessness when you know you cannot personally change the outcome of your fate knowing the future results in death. Most of the reality of the brutal war is exposed through battles or bluntly stated by another distraught soldier. A sense of urgency is not present when knowing that at any moment a comrade could be returning with â€Å"screams of intolerable pain. [Knowing] every day that he can live will be howling [with] torture† (72). The lack of urgency communicates that death is a causal event during war and the witnesses are used to the terrible sight of mangled or dead bodies. Some even accept that they will one day become like those they see in pain and fear life over death. â€Å"Every face can be read† on the appearance of each soldier who knows they are subject to the â€Å"embrace† of â€Å"the front† (53). Faces can easily be read because the same fate awaits all the soldiers, death and no hope. The characters see no future and are trudging along in an empty cycle. The circle is completed with unfilled desires to keep living when the discovery of Paul with â€Å"his face [of calm expression] as though almost glad the end had come† establishes that he was happy to leave pain, suffering and damaged forthcoming opportunities to a peaceful afterlife (296). The lost generation shared a â€Å"common fate [which] ruined [them] for everything† upcoming in the future to better their lives such as a family or a job offer as mentioned by various characters but created disappointment at the realization their dreams would not come true. This contributed to the plummeting feelings the lost generation carried with them. Hemingway disguises his characters want for redemption and amount of hopelessness they feel. The book has a more up beat consistency than â€Å"All Quiet on the Western Front† and more is said in what the Jake is not saying than what he and Brett bluntly state. Brett cannot be with Jake because she would â€Å"tromper† or commit adultery since Jake cannot satisfy her needs sexually (62). Instead Jake secretively takes a prostitute out to dinner but ends up dumping her on his friends while he leaves with Brett. Jake did not sleep with the prostitute, Georgette, because he felt ashamed and helpless about his physical injury from the war. He does not feel man enough to sleep with a prostitute, he feels discouraged about his future plans and ability to gain happiness as part of the lost generation. To fill the void opened from war, Jake, Brett and their comrades drink to escape their persisting troubles and pains. Jake has a miserable life and to make it better he finds it easier to get drunk and not fix his problems. â€Å" ‘Don’t get drunk, Jake,’ she [Brett] said. ‘You don’t have to. ’†¦ ‘Don’t,’ she said. You’ll be alright. ’† Brett reassures Jake (245). The pain and emptiness ceases with alcohol and distracts from the wars wounds. Contrasting to Paul and the other lost generation soldiers in â€Å"All Quiet on the Western Front†, Jake proves he is able to redeem himself and looks to the future. Ja ke uses religion as a parallel to his emotional stability. When starting out Jake was not religious and just went through the movements of going to church and â€Å"being a good Catholic†, however as he progresses he finds that he should care more about religion and has a want to be more involved. The parallel of him wanting to be more involved is when he breaks away from Brett and starts off new; and for the first time believes in his future after he returned from the war. Jake’s break through occurred when he â€Å"stoop up, gripped with [his] toes on the edge of the raft as it tipped with [his] weight, and dove cleanly and deeply, to come up through the lightening water, blew the salt water out of [his] head, and swam slowly and steadily to shore† (242). As Jake comes out of the water, he symbolizes a baptism and the rebirth of himself into a more understanding and less negative man. Along with becoming less frightened of the future Jake was able to let go of Brett and her ability to draw men in. He finally cleansed himself of her and his past troubles and looks to days ahead. Rarely does Jake interact with a genuine character, more often does he associates with deceptive, greedy, manipulative or mean people of the lost generation. The main character that is sympathetic is Jake, he battles the most with his physical injury and because of that, Brett puts him through emotional misery. Even as Brett â€Å"kissed [Jake he] could tell she was thinking of something else† and finally understood that she just used him for her own personal benefit (245). After his â€Å"baptism† Jake was close to moving on from Brett and almost did until she pulled him back in again. The fact that Brett is thinking about someone else is the last straw for Jake and he is done with her. From this kiss on, Jake is cold and a little immature towards Brett. This signifies his final connection with her emotionally and he takes steps to begin a new life. Brett consciously talks bout her other men with Jake while she knows how he feels about her. She almost flaunts them in front of Jake by complimenting them saying â€Å"he’s my sort of thing† (247). Brett is attracted to the bad boys who show her attention but aren’t controlling. She disregards Jake as a candidate for her commitment and love since he cannot satisfy her sexually; she only uses him emotionally t hen ditches him when a better offer comes along. She is aware she cannot be with him and it hurts him to see her go off with men, however she does nothing to change this. She even goes as far as to bring the men over to Jake’s place to have a drink. Because of her blatant disrespect for anyone but herself she is not a redeemable character and no sympathy is given to her. Jake is the only character that deserves sympathy while Brett does not even deserve respect from Jake. Similar to sympathy, Jake becomes a redeemable character towards the end of his journey with Brett after the war. He clearly stands opposed to Brett who is neither sympathetic nor redeemable. During Jake’s baptism and revelation, he proves to want to redeem himself, if not to others at least to himself. He is aware that he is not the most religious man but tries to convince himself otherwise to morally feel better. Jake is Catholic and by the end of the book becomes more religious and understands the meaning of religion rather than just going through the motions at church. He values the importance of God when Brett states she does not really care for him or religion since it’s a waste of her time. Jake at least holds on to that the whole book and increases his religious activities and symbolism towards the end. Not only does Jake morally and mentally redeem himself but he also redeems his time wasted on Brett. One of their last interactions Jake unmistakably communicates his annoyance and irritation with Brett, â€Å" ‘You like to eat, don’t you? ’ she said. ‘Yes,’ I said. ‘I like to do a lot of things. ’ â€Å" (250). Jake becomes fed up with Brett’s constant lack of acknowledgement that he is always there for her and not some one to use when her love life is not thriving. He grows tired of constant games and realizes there is nothing left for them together. After more small talk is exchanged between the two, Jake is ready to let her go for good and finally gains enough confidence that everything will be okay with out Brett. Brett tries to make herself sound more appealing to Jake by explaining, â€Å"it makes one feel rather good deciding not to be a bitch† (249). Other than making the decision to not be a bitch, Brett makes no other attempt to redeem herself or acknowledge that she played with Jake’s feelings and ruined part of his life for holding on to him for such a long time. She cannot get over her self absorption to realize she messes with men for her own benefit whether it be money or sex, and doesn’t care who she hurts along the way, mainly Jake. There is no evidence that she is a redeemable, sympathetic or a caring character. Although she has issues because she, too, is considered the lost generation, that does not give her the right to act above everyone else and hurt Jake. Jake also traumatized by the war does not use women to make Brett jealous or ever hurts her. He is always there when he is needed to support her dramatic lifestyle. Brett has no compassion for anyone but herself therefore making her unredeemable and Jake redeemable. Although each stories have their differences in almost all aspects there is one overall main point: the lost generation was hopeless and it was a difficult time for those people. Each book expresses the same bigger picture but is differently executed. Jake’s tone which represents the overall feel of the book communicates the idea of a ghostly and missing man looking for a happier path in life to escape his sadness and pain. He rarely finds little pleasures and mostly describes scenes as dark or dark imagery, only a few times is light mentioned when redemption or renewal of a character is occurring. Paul’s description of the war gives off a more pessimistic tone as he always comes back to the idea that the lost generation has nothing to return to at home. However he finds simple pleasures more enjoyable and tries to make the most of them. Both characters portray a sense of despair and loss of direction in life but differently executed. Hemingway chooses to exhibit his characters as striving to change their lives while Remarque’s turns negatively towards death and meaninglessness. Hemingway does not refer to the war but instead barely mentions it or Jake will see military like actions between people symbolizing the war and the lost generation. The fact that Hemingway does not mention the war, yet the book is about war, further proves that in Hemingway’s writing, what is not being said is more important. The tone is important to both novels to relay the same message but entirely different outcomes and themes. The lost generation was a sad hopeless group of veterans who, if not killed, had to aimlessly go through life feeling like there was no purpose or they didn’t belong. Hemingway and Remarque’s classic novels illustrate the hard times during and after the war and the many similarities that are present.

Where to Find Essay Topics Old Testament

Where to Find Essay Topics Old Testament Why Almost Everything You've Learned About Essay Topics Old Testament Is Wrong The prophets spoke out against the social conditions they observed and the methods by which people dealt with one another. Although there's no mention of a hell in the Bible, it is founded on a genuine place. Too frequently, Christians are merely pleased with having Christ's love rather than attempting to understand it. While of course many would say that there's a very clear illustration of God having the ability to modify morals in human history, I've found something that would not merely earn a check-mate on the problem of whether the Old Testament is just a different time frame of morals and people, but show that canon law should be questioned. Clearly it's an enthronement psalm. 1 word gives us a clearer comprehension of exactly what this verse means. It's evident from the above mentioned scriptures and the verses that will follow afterwards it's not wrong to eat all kinds of meat. The bible isn't an exception to this. It isn't something which you can do alone. So let's dig in the etymology a little. After all knowledge widens your horizon and it's good to understand what another individual's scripture talks about. The issue of evil plays a massive role in the Old Testament. It is dependent on how you're feeling about eating a specific meat or meats generally. One of many complaints against eating a biblical diet is that it isn't affordable. Both meat practices are a part of Jews and Muslim rituals of eating meat all around the world. An extra concern comes out of the glycerin that's added to make such emulsifiers. It appears that a ram proved to be an ideal substitute. The most frequently encountered problem, nevertheless, is the falsification and forgery of Wills in addition to the simplicity of destroying paper. Generation in this bigger sense is virtually the exact same as race. His work is completely free and all online for more research. It's been a very long wait, but I believe it was worth it! The brief answer is none of those. Merely a cursory glance at both of these distinct renderings begins to reveal a number of the ambiguity in translating this text. By the way, this isn't a mere failure on the portion of man. The presumption is that each individual that's born and living within this planet is a descendant of Adam. All men ought to be ready to defend themselves and their families from thugs and criminals and perhaps even false teachers that are coming in as wolves to destroy them through teachings that are only flat out wrong since they haven't studied enough to be aware of the reality. Premarital sex isn't a sin. We must work towards having honest speech with one another. In response to such ideas, this essay seeks to learn more about the use of OT prophets by addressing these aspects as depicted biblically. What follows represents an overview of critical biblical scholarship on the matter. With a wide range of inquiry feasible for Biblical studies, the student should choose the suitable foundation on which to explore their topic. Things You Won't Like About Essay Topics Old Testament and Things You Will Tin will always resist corrosion and at times it functions as a protective armor for different metals. The lyrical content is a bit less political than the prior albums. A good example of this would be tin cans because tin cans are produced from steel then to cover the steel tin is put on the inside and beyond the can, so rusting won't occur. Severe Christians can't ignore the Bible. Sin and the way that it can be atoned for. God would like you to prosper. Singing praise to God isn't only for other people to hear.

Essay about International Relations Beirut, Lebano and...

â€Å"Beirut wasn’t sensible and it never did serve a purpose. It was goofy from the beginning.† (Gen. Colin Powell) That quote summarizes the United States time spent in beirut, Lebanon. Lebanon was not a country of prevailation at the time of the United States arrival. The entire country was ruled by regional militias and was overrun by its public. America, France, and Britain all arrived to help Lebanese government take control of their own country again. All of these 3 world superpowers were there after the PLO pulled out of Lebanon, and these superpowers were known as an alliance called Multinational Force in Lebanon (MNF). Lebanon was not a country of relief but a country of stress and despair. This country needed help and it was†¦show more content†¦With the information of that informative statement, MNF had also detected that Syrian government was suspected. (CNN Library) Why would Siberia be involved? Siberia was involved after Ronald Reagan pledging a nd lying about ordering withdrawal of all U.S. troops from Lebanon. After that, upon request of Lebanon, Reagan was offered to go back to Lebanon because Lebanon had wanted authorization for the MNF to help regain control of Lebanon. The UN had authorized Reagan to deploy 1800, because Reagan had seen it as a limited time mission. (Micah Zenko) We’re still wondering, what made Reagan redeploy marines into Lebanon? Well, what brought them back was the assassination of Lebanese President Bachir Gemayel, the massacre of refugees, and regional chaos. So, we still ask, what was our reasons of a long stay in Lebanon? This is all answered simply by the fact that America has a dominant, big daddy, eyes on ego ever since we were colonized. This ego has led to many successes and very few failures. sadly, this attack being a failure. There were claims on U.S. Marine officers claiming that they did not take proper steps to protect the barracks against terrorists attacks. (CNN Library) Ob viously, since that tragic attack, as an international network with advancements in technology, we have have changed pour security and improved it with the privileges of having such high tech hardware and software to keep not only